What measures are being implemented to protect residential property tenants?
On 18 March 2020, the Government announced that it would pass emergency legislation which would prevent landlords, both social and private, from bringing possession proceedings against tenants who are unable to pay their rent. The Housing Secretary, Robert Jenrick, stated that “no renter who has lost income due to coronavirus will be forced out of their home, nor will any landlord face unmanageable debts.”
The announcement came after several organisations, including housing charity Shelter, expressed concerns that more than 50,000 households could face possession proceedings due to the economic uncertainty following the Covid-19 outbreak.
Related FAQs
The current situation with the coronavirus pandemic has presented obvious challenges to the effective and fair operation of the Court of Protection (COP). Remote access to the COP has therefore become a necessity to ensure that hearings continue to provide proper access to justice. All parties involved in such cases have a responsibility in achieving this primary aim.
- Delays in preparing and submitting applications to comply with pre-commencement conditions. In this respect there can be lengthy timescales gathering evidence to support applications to comply with pre-commencement conditions, ecology, contamination and archaeology are examples of matters which can require significant periods of survey work
- Following on from the above the ability to get required experts on the site necessary to undertake the required survey work
- Delays in the determination of applications to comply with pre-commencement conditions. In this respect whilst there are deemed discharge provisions/procedures concerning certain matters, the provisions cannot be used to discharge all types of conditions
- The ability to get people on site to undertake material operations
In the circumstances, it is advisable to start considering the implementation of the planning permission early and the earlier the better. Under current legislation whilst it is possible to vary conditions, albeit potentially leading to wider issues, it is not possible to extend the life of a planning permission meaning that lawful implementation is essential to avoid the loss of that permission.
If a planning permission is lost, amongst other things it may not be granted again or may not be granted on similar terms. In the circumstances, it is advisable to seek advice given the specific facts of the case to minimise the risk of a planning permission not being lawfully implemented and expiring.
Court hearings have been conducted remotely, with the judgment in Kerry v SSCLG being given via telephone. The Senior President of Tribunals issued emergency Practice Directions which will apply to Property and Lands Chambers’ respectively. This has made provision for remote hearings. Inspections of properties have been suspended with immediate effect, with photographs, videos or external visits permitted where appropriate. Where inspections are essential, the case should be stayed.
Payments of the Community Infrastructure Levy (“CIL”) are tied to commencement of development, and where an instalment policy is in place, the instalments are usually tied to periods of time following commencement rather than build out rates. Therefore where a development has commenced, payments of CIL are likely to fall due in respect of a site notwithstanding that the site may have temporarily closed or build out rates have slowed.
New regulations now in force, provide some additional relief for those developers with an annual turnover of £45 million or less. Such relief will allow the Council to defer payments, disapply late interest charges, and refund late interest charges that have already been levied since 21 March 2020.
For those developers that cannot benefit from the new provisions, unless a Council has adopted an exceptional circumstances relief policy the regulations do not provide for any relief to be provided in instances where payment of CIL will create viability issues. Most Councils have not adopted such a policy, and in those circumstances the CIL liability will remain due in accordance with the payment schedule on the demand notice.
Councils are at liberty to amend their instalment policies in accordance with their own internal procedures, and the Government is encouraging Councils to explore this option to provide some relief to developers. However this will only assist in respect of any prospective instalments where the development commences after the new instalment policy has been adopted.
For those developers whose annual turnover exceeds £45 million, the Government seems to be taking the view that such developers can afford their CIL liabilities regardless of the current climate. The only concession the Government has proposed is to encourage Councils to make use of the existing discretion they have in respect of the imposition of surcharges for late payments.
No. No action need be taken in relation to the demand but we would advise against presentation of a petition based upon any Statutory Demand issued between 1 March 2020 and the end of the restrictions. As you may be aware, with Winding Up there is no requirement to issue a Statutory Demand notice before proceeding so this is unlikely to create too many issues – click here to see whether you should issue petitions on other grounds.
There is nothing to prevent statutory demands being served at this time. However, there may be limited benefit as it cannot form the basis of a future winding up petition.