I have trespassers occupying my land. Can I evict them?

• Delays in preparing and submitting applications to comply with pre-commencement conditions. In this respect there can be lengthy timescales gathering evidence to support applications to comply with pre-commencement conditions, ecology, contamination and archaeology are examples of matters which can require significant periods of survey work
• Following on from the above the ability to get required experts on the site necessary to undertake the required survey work
• Delays in the determination of applications to comply with pre-commencement conditions. In this respect whilst there are deemed discharge provisions/procedures concerning certain matters, the provisions cannot be used to discharge all types of conditions
• The ability to get people on site to undertake material operations

In the circumstances, it is advisable to start considering the implementation of the planning permission early and the earlier the better. Under current legislation whilst it is possible to vary conditions, albeit potentially leading to wider issues, it is not possible to extend the life of a planning permission meaning that lawful implementation is essential to avoid the loss of that permission.

If a planning permission is lost, amongst other things it may not be granted again or may not be granted on similar terms. In the circumstances, it is advisable to seek advice given the specific facts of the case to minimise the risk of a planning permission not being lawfully implemented and expiring.

In the event that the worst happens and contractor insolvency occurs, there are a number of steps which the employer should take immediately:

• Confirm that insolvency has actually occurred and the type of insolvency (for example liquidation or adjudication) – actions taken based on rumours can have adverse consequences
• Secure the site and carry out an audit of the plant, equipment and materials present – this may extend to changing the locks on site in order to prevent overzealous contractors and sub-contractors seeking to return and take what they see as their possessions. The building contract may contain a provision that these are the employer’s property, but they can be difficult to recover if they are not within the employer’s possession – possession is 9/10ths of the law!
• Ensure that there are adequate insurance and health and safety arrangements in place for the site – these would usually be dealt with by the contractor and therefore may no longer be in place, so alternative arrangements may be required
• Ensure that any further payments to the contractor are stopped pending a more detailed review
• Consider whether any off-site materials have already been paid for and can be secured. This can however be difficult in practice where the materials are not physically within the employer’s possession

In addition, there are also a number of further actions which the employer should consider in the slightly longer term:

• Investigate the options available and ascertain the cost of completing the works to assist in deciding how best to proceed
• Consider whether termination of the contractor’s employment under the building contract is required, and if so take the necessary steps in accordance with the building contract
• Consider whether there are any bonds or guarantees in place upon which the employer can rely, and if so assess their terms as to whether and how to make a claim
• Make arrangements to complete the works – as a general rule of thumb the cost of completing the works may increase by around 30% if it is necessary to get a replacement contractor
• Consider whether direct payment to subcontractors is possible or desirable
• Although we would say this(!) we would strongly recommend taking legal advice, as insolvency and its implications are complex and it is easy to inadvertently fall foul of the various different requirements

Although an employer is obliged to conduct consultation “with a view to reaching an agreement”, it is not required to actually agree to any counter proposals made by the employee representatives. Merely to consider them in good faith.

The ICO is providing new guidance to organisations regarding data protection and coronavirus, which can be accessed here: https://ico.org.uk/for-organisations/data-protection-and-coronavirus/

Information about the Covid-19 health status of individuals is special category data under the GDPR. This means it is high risk which has implications for how you use it, store it and keep it secure.

You will already hold health data about your employees as this is necessary to provide a safe, accessible place to work and to make reasonable adjustments to the workplace. You now need to make sure that the information you gather about your employees, visitors to your sites, customers and suppliers about Covid-19 is processed in accordance with data protection laws.

£370 million will be available to support small and medium-sized charities who are at the heart of local communities and which are making a big difference during the outbreak, including those delivering food, essential medicines and providing financial advice. These monies will  be distributed by organisations including the National Lottery Community Fund for those in England. It is understood these monies will need to be applied for. The application system for the National Lottery Community Fund grant pot is expected to be operational within a period of weeks.