Do you think MHFA will become a legal requirement for businesses eventually?

• Delays in preparing and submitting applications to comply with pre-commencement conditions. In this respect there can be lengthy timescales gathering evidence to support applications to comply with pre-commencement conditions, ecology, contamination and archaeology are examples of matters which can require significant periods of survey work
• Following on from the above the ability to get required experts on the site necessary to undertake the required survey work
• Delays in the determination of applications to comply with pre-commencement conditions. In this respect whilst there are deemed discharge provisions/procedures concerning certain matters, the provisions cannot be used to discharge all types of conditions
• The ability to get people on site to undertake material operations

In the circumstances, it is advisable to start considering the implementation of the planning permission early and the earlier the better. Under current legislation whilst it is possible to vary conditions, albeit potentially leading to wider issues, it is not possible to extend the life of a planning permission meaning that lawful implementation is essential to avoid the loss of that permission.

If a planning permission is lost, amongst other things it may not be granted again or may not be granted on similar terms. In the circumstances, it is advisable to seek advice given the specific facts of the case to minimise the risk of a planning permission not being lawfully implemented and expiring.

The fee payer that pays the fee to the contractor’s PSC for the services (end user client or agency) will be responsible for operating PAYE and deducting NIC’s. The fee payer must also pay employer NIC’s and where applicable the apprenticeship levy so there will be additional costs involved in the event of a change to employed status for tax purposes.

If the assessment concludes that the contractor is self-employed, the PSC can continue to be paid gross.

We hope that all organisations will come out of lockdown successfully. However, the current economic crisis means that many organisations will face very difficult trading conditions.

Employment costs are one of, if not the, largest cost to your organisation. These costs will have an effect on your financial well-being – and many organisations are now considering how to reduce employment costs. That said, your workforce is also your most important asset and as we get back to business, you will need your workforce to run the organisation, produce your goods, deliver your services and deal with your customers.

As a result, many organisations are facing a very difficult situation – how to reduce or flex the cost of the workforce whilst also maintaining an ability to service customers. This difficulty is enhanced by the uncertainty of when the pandemic will be controlled and the threat of lockdowns end.

 Aside from the CBILS Scheme, the Government have, or are in the process of, implementing several different schemes to support businesses financially through the Covid-19 outbreak.

In the event that the contractor is displaying one or more of the above signs, then it is worth considering the following actions to protect the employer’s position as far as possible:

• Closely monitor the financial and on-site performance of the contractor in order to assess the likelihood and timing of potential insolvency
• Ensure all bonds, guarantees and collateral warranties have been obtained under the building contract, and if not take steps to obtain them immediately
• Consider the terms of any guarantees to ensure that the guarantor’s obligations are not inadvertently discharged
• Bonds may require adjudication to have been commenced (or even completed) prior to insolvency so as not to be stayed pursuant to insolvency laws
• Carry out an audit of the on-site plant, equipment and materials, and evidence this (for example with photographs and written records)
• Ensure that copies of all relevant documentation have been obtained, for example drawings, specifications and anything required to comply with CDM requirements. If not, take steps to obtain these
• Review the payment position under the building contract, including whether any over payments have been made to the contractor which should be reclaimed, what retention is held or has been released, whether any payment notices may be necessary, and whether there are rights of set-off which should be exercised
• Check whether the involvement of any third party is required, for example funders, landlords, tenants or purchasers who may have rights in relation to the building contract and how it is administered
• Review the terms of the building contract relating to contractor insolvency – hopefully the parties will be fully aware of the building contract terms and have been administering it correctly to date, but if it has been hiding in a draw then now would be a good time to dust it off and ensure familiarity with the relevant provisions!

In general. there is often a stick or twist decision.  If the employer chooses to financially support the contractor (for example by agreeing different payment arrangements), this may help to keep the contractor solvent and more likely to complete the project, but it also exposes the employer to greater risk if the approach is not successful.  Conversely, withholding payments  from the contractor may make insolvency a self-fulfilling prophecy.  The precise advantages and disadvantages of the approach will be dependent on the specific circumstances of each case.